City Hall East Side Window Replacement

2026-11-03

The City of Antioch is seeking qualified contractors to provide all labor , materials , equipment , and incidentals necessary to remove and replace the five ( 5 ) existing east - side windows and storefront assemblies at Antioch City Hall . The existing façade is a non - structural , brick veneer over framed construction . Contractor shall exercise care to avoid façade damage and ensure proper weatherproofing and integration with the existing building envelope . All work shall comply with current applicable building codes , industry standards , and manufacturer installation requirements . Contractors and / or subcontractors performing work under this contract must possess and maintain a valid State of California Contractor ’ s License , Class B ( General Building Contractor ) and / or Class C - 17 ( Glazing Contractor ), as applicable to their scope of work , at the time of bid submission and throughout the duration of the project . In accordance with California Labor Code Sections 1725 . 5 and 1771 . 1 , all contractors and subcontractors performing work on this public works project must be registered with the California Department of Industrial Relations ( DIR ) prior to bidding and throughout the duration of the contract . This project is subject to compliance monitoring and enforcement by the DIR . All labor performed under this contract shall be in accordance with current prevailing wage rates as determined by the State of California , Department of Industrial Relations . Customer Service & Quality Assurance Any work or assigned duties that are not performed to our standards and / or contractual agreement may result in delay , reduction , or discount at the Contractor ’ s expense . The judgment for reduced payment or discount shall be at the City ’ s sole discretion . In addition , the City may move to the next lowest responsible bidder if the City is not happy with the services or communication supplied by the contractor . All complaints about services rendered will be processed by the Public Works Director or designee / s . Contractor Will Provide A safe and motivated crew capable of performing all work per specifications . After approval to start work the contractor is to supply the City representative with a work schedule that must include starting times , dates and locations . Contractor is to keep the City informed of working locations so that the City representative can inspect the work throughout the process . At least one crew member must speak English . All labor , equipment and materials are required to perform the work as specified in a safe and productive manner . Contractor will be responsible for onsite safety , traffic control and quality control . All work must be in accordance with all state and local laws , codes and specifications . Workers are to wear reflective vests at all times . Vehicles must be clearly labeled with company name and vehicles numbers . Equipment & Supplies Contractor agrees to provide and maintain all equipment required to perform the above services . The contractor ’ s equipment is to be of top quality and in good working order at all times . If the City or its designee requests replacement equipment due to poor quality or performance the contractor will replace the equipment at his / her own expense as soon as possible .

California

2026-03-27