Mobile Ferromagnetic Detectors

2026-11-03

Unicor , SV0209 - 26Mobile Ferromagnetic DetectorsSolicitation posted on SAM . gov : 4 / 13 / 2026Deadline for quotes : 4 / 24 / 2026SOLICITATION : Issued as Request for Quote ( RFQ ) for a Firm - Fixed - Price , Definite Delivery - Definite Quantity type contract . Set Aside : This is an UNRESTRICTED solicitation . Requirement : Federal Prison Industries ( FPI ) is seeking to purchase 7 mobile ferromagnetic detectors , shipped FBO Destination to : Qty 3 , shipped to Unicor Recycling Schuylkill , I - 81 and PA 901W , Minersville , PA 17954 ; Qty 2 , shipped to Unicor Recycling Texarkana , 4001 Leopard Dr , Texarkana , TX 75501 ; Qty 2 , shipped to Unicor Recycling Marianna , FL , 3625 FCI Road , Marianna , FL 32446 . SALIENT CHARACTERISTICS / WORK DESCRIPTION : Mobile Ferromagnetic Detectors must be :- able to passively screen persons for ferrous metals as they pass by ;- mobile ;- indicate where a ferrous metal was detected ; Questions for this solicitation will be addressed in writing to : wesley . newell2 @ usdoj . gov . AWARD METHODOLOGY : This acquisition will be procured in accordance with FAR Part 12 – Acquisition of Commercial Items and Part 13 – Simplified Acquisition Procedures . The Government intends to evaluate quotes and award a contract that is the best overall value to the government , in accordance with FAR 52 . 212 - 1 ( g ). Evaluation factors are price , technical capabilities , and lead time . The Government reserves the right to require the quoter to submit additional information as necessary to support a pre - award determination of responsibility . PERIOD OF PERFORMANCE : UNICOR ’ s desired delivery is as soon as possible . Vendors are required to provide their best delivery time for evaluation . Delivery schedule will be established at time of award . OFFERS : Signed and dated offers are submitted by email to : wesley . newell2 @ usdoj . govThe date and time for receipt of quotes is : Friday , April 24 , 2026 , at 2 : 00 p . m . EASTERN STANDARD TIME ( EST ). Do not send offers via U . S . mail . OMB Clearance 1103 - 0018 . Offer must indicate Solicitation No . SV0209 - 26 , time specified for receipt of offer , name , address , telephone number of offeror , technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation , terms of any expressed warranty , price and any discount terms . Offer must include acknowledgment of all amendments , if any . THE FOLLOWING INFORMATION IS REQUIRED TO BE COMPLETED BY THE OFFEROR : SAM UNIQUE ENTITY IDENTIFIER ( UEI ): _______________________________________VENDOR POINT OF CONTACT : _____________________________________VENDOR TELEPHONE & FAX NUMBER : _____________________________VENDOR EMAIL ADDRESS : ________________________________________VENDOR BUSINESS SIZE FOR NAICS CODE 485991 : Small Business ( Y or N ): _____________By submission of an offer , the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database ( System Award Management ) prior to submitting a quote , during performance and through final payment of any contract resulting from this solicitation . The Contracting Officer is Wesley Newell at wesley . newell2 @ usdoj . gov . PART I : INFORMATIONThis is a combined synopsis / solicitation for commercial items prepared in accordance with the format in Subpart 12 . 6 as supplemented with additional information included in this notice . This announcement constitutes the only solicitation ; offers are being requested and a written solicitation will not be issued . The solicitation number is SV209 - 26 and this solicitation is issued as a Request For Quote ( RFQ ). The North American Industry Classification System code is 334519 , Other Measuring and Controlling Device Manufacturing ( small business size 500 ). This requirement is UNRESTRICTED . This solicitation should result in a Purchase Order . It will not be an ongoing contract . NOTICE TO GOVERNMENT WHEN CONTRACTOR ( S ) DELAYS : In the event the contractor ( s ) encounter difficulty in meeting performance requirements , or when there is an anticipated difficulty in complying with the delivery terms or completion dates , or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery / performance of this contract , the contractor must immediately notify the Contracting Officer at UNICOR in writing , giving pertinent details . This information will not be construed as a waiver by the Government of the required delivery schedule , or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract . INVOICES ARE TO BE EMAILED TO : Accounts . payable @ usdoj . gov

Pennsylvania

2026-05-09