Morrill Hall - Parapet and Roof ( Repair and Replacement )

2026-11-03

The Board of Regents of the University of Minnesota ( the “ University ”) is requesting Proposals to provide construction services for parapet and roof repair at Morrill Hall , located on the east bank of the Twin Cities campus ( the “ Project ”). Project Description ( the “ Work ”) The University is requesting General Contractor services to provide repair and replacement of various areas of roofing , stone , brick , paint , drainage , sealants and other exterior enclosure components at Morrill Hall . The building address is 100 Church Street SE , Minneapolis , MN 55455 and is included as a contributing part of SHPO ' s historic Northrop Mall . The building functions in a critical role for the University Administration and is a central hub of campus . The selected Respondent will need to work closely with FM , CPM , PTS , PSRE and Landcare to ensure a thoughtful staging and construction plan . Staging and construction plans should be included with Respondent ’ s Proposal . Minimizing disruption to building occupants and providing an efficient construction plan that completes the work over Summer break 2026 , is critical . Contractor should note that there is ACM present on the Project and the selected Respondent will be required to work closely with University HMP to schedule abatement work . Refer to the Haz - mat report included within specifications . Miller Dunwiddie Associates is the Architect / Engineer of Record for the Project . University - Provided Information The University has assembled the following information about the Project ( collectively , the “ RFP Documents ”) for review by the Respondent : This RFP and all Attachments RFx Instructions , Requirements , and Rights Reserved by the University Current Prevailing Wage Rates 100 % Construction Documents ( Drawings and Project Manual dated 02 - 13 - 2026 )

Minnesota

2026-05-02